Hysbysiad dyfarnu contract
Canlyniadau'r weithdrefn gaffael
Adran I:
Endid
contractio
I.1) Enw a chyfeiriad
Rotherham Metropolitan Borough Council
GB173552264
Riverside House, Main Street
Rotherham
S60 1AE
UK
Person cyswllt: Toni Cox
Ffôn: +44 1709334196
E-bost: toni.cox@rotherham.gov.uk
NUTS: UK
Cyfeiriad(au) rhyngrwyd
Prif gyfeiriad: https://www.rotherham.gov.uk/
Cyfeiriad proffil y prynwr: https://uk.eu-supply.com/ctm/Company/CompanyInformation/Index/104118
I.4) Y math o awdurdod contractio
Awdurdod rhanbarthol neu leol
I.5) Prif weithgaredd
Gwasanaethau cyhoeddus cyffredinol
Adran II: Gwrthrych
II.1) Cwmpas y caffaeliad
II.1.1) Teitl
Damp Proof Services
Cyfeirnod: 22-013
II.1.2) Prif god CPV
50000000
II.1.3) Y math o gontract
Gwasanaethau
II.1.4) Disgrifiad byr
The contract covers attending to Council owned properties to conduct a damp survey following a referral from the CIC Team. Following a survey, the incumbent will supply a full detailed report (as set out in the Service Requirements) which details their findings and any remediation works required. Remediation costs will also be supplied. Once the CIC Team gives the incumbent authorisation to proceed with the works, the incumbent will be responsible for arranging access with the tenant, carrying out all the works in line with our Service Requirements as well as liaising with tenant at pre-commencement stage to ensure a smooth transition of works with minimal disruption to both the incumbent and the tenant. The incumbent will be responsible for all management, supervision and Health and Safety costs associated with each job.
II.1.6) Gwybodaeth am lotiau
Mae’r contract hwn wedi’i rannu’n lotiau:
Na
II.1.7) Cyfanswm gwerth y caffaeliad
Gwerth heb gynnwys TAW: 1 586 410.00 GBP
II.2) Disgrifiad
II.2.2) Cod(au) CPV ychwanegol
50000000
II.2.3) Man cyflawni
Cod NUTS:
UK
II.2.4) Disgrifiad o’r caffaeliad
The contract covers attending to Council owned properties to conduct a damp survey following a referral from the CIC Team. Following a survey, the incumbent will supply a full detailed report (as set out in the Service Requirements) which details their findings and any remediation works required. Remediation costs will also be supplied. Once the CIC Team gives the incumbent authorisation to proceed with the works, the incumbent will be responsible for arranging access with the tenant, carrying out all the works in line with our Service Requirements as well as liaising with tenant at pre-commencement stage to ensure a smooth transition of works with minimal disruption to both the incumbent and the tenant. The incumbent will be responsible for all management, supervision and Health and Safety costs associated with each job.
II.2.5) Meini prawf dyfarnu
Maes prawf ansawdd: Quality
/ Pwysoliad: 40
Maes prawf ansawdd: Social Value
/ Pwysoliad: 20
Price
/ Pwysoliad:
40
II.2.11) Gwybodaeth am opsiynau
Opsiynau:
Na
II.2.13) Gwybodaeth am Gronfeydd yr Undeb Ewropeaidd
Mae'r broses gaffael yn gysylltiedig â phrosiect a/neu raglen a ariennir gan gronfeydd yr Undeb Ewropeaidd:
Na
Section IV: Gweithdrefn
IV.1) Disgrifiad
IV.1.1) Y math o weithdrefn
Gweithdrefn agored
IV.1.8) Gwybodaeth am Gytundeb Caffael y Llywodraeth (GPA)
The procurement is covered by the Government Procurement Agreement:
Ydy
IV.2) Gwybodaeth weinyddol
IV.2.1) Cyhoeddiad blaenorol mewn perthynas â’r weithdrefn hon
Rhif yr hysbysiad yn OJ S:
2024/S 000-000771
Section V: Dyfarnu contract
Rhif Contract: 1
Teitl: Damp Proof Services
Dyfernir contract/lot:
Ydy
V.2 Dyfarnu contract
V.2.1) Y dyddiad y daeth y contract i ben
02/04/2024
V.2.2) Gwybodaeth am dendrau
Nifer y tendrau a ddaeth i law: 3
Nifer y tendrau a ddaeth i law drwy ddulliau electronig: 3
Dyfarnwyd y contract i gr?p o weithredwyr economaidd:
Na
V.2.3) Enw a chyfeiriad y contractwr
Preservation Treatments Ltd trading as ProTen Services
01042309
ProTen Services,Whitehall Estate, Unit 1 Ashfield Cl, Whitehall Rd, Leeds
Leeds
LS12 5JB
UK
E-bost: gary.laird@protenservices.co.uk
NUTS: UK
BBaCh yw’r contractwr:
Ydy
V.2.4) Gwybodaeth am werth y contract/lot (heb gynnwys VAT)
Cyfanswm gwerth y contract/lot: 1 586 410.00 GBP
V.2.5) Gwybodaeth am is-gontractio
Section VI: Gwybodaeth ategol
VI.4) Gweithdrefnau adolygu
VI.4.1) Corff adolygu
High Court
The Royal Courts of Justice, The Strand,
London
WC2A 2LL
UK
VI.4.2) Corff sy’n gyfrifol am weithdrefnau cyfryngu
High Court
Royal Courts of Justice, The Strand
London
WC2A 2LL
UK
VI.4.3) Gweithdrefn adolygu
Gwybodaeth fanwl gywir am y terfyn(au) amser ar gyfer gweithdrefnau adolygu:
Precise information on deadline(s) for lodging appeals: The Contracting Authority will incorporate a minimum 10 calendar day standstill period at the point information on the award of the Contract is communicated to tenderers. Applicants who are unsuccessful shall be informed by the Contracting Authority as soon as possible after the decision has been made as to the reasons why the applicant was unsuccessful. If an appeal regarding the award of the contract has not been successfully resolved, the Public Contracts Regulations 2015 (as amended) provide for aggrieved parties who have been harmed or are at risk of harm by breach of the rules to take legal action. Any such action must be brought within the applicable limitation period. Where a contract has not been entered into, the Court may order the setting aside of the award decision or order the Contracting Authority to amend any document and may award damages. If the Contract has been entered into, the Court may, depending on the circumstances, award damages, make a declaration of ineffectiveness, order the Contracting Authority to pay a fine, and/or order that the duration of the Contract be shortened. The purpose of the standstill period referred to above is to allow the parties to apply to the Courts to set aside the award decision before the contract is entered into.
VI.4.4) Y gwasanaeth lle y gellir cael gwybodaeth am y weithdrefn adolygu
High Court
The Royal Courts of Justice, The Strand,
London
WC2A 2LL
UK
VI.5) Dyddiad anfon yr hysbysiad hwn
08/05/2024